Notice of Bid/Request for Proposal

OTHER AGENCIES AND ORGANIZATIONS
PROJECT NUMBER: 206032

REQUEST FOR BIDS

PROPOSALS ARE REQUESTED FROM QUALIFIED LICENSED GENERAL CONTRACTORS BY THE State of Florida, Department of Military Affairs HEREINAFTER REFERRED TO AS OWNER, FOR CONSTRUCTION OF:

PROJECT NUMBER: 206032              ACCOUNTING CODE: FARP 08

PROJECT NAME AND LOCATION: Renovations and Additions to the Palmetto National Guard Armory, 1107 14th Avenue West, Palmetto, Florida 34221-4544.

PREQUALIFICATION: Each bidder whose field is governed by Chapters 399, 455, 489, and 633 of the Florida Statutes, for licensure or certification must submit prequalification data of their eligibility to submit proposals ten (10) calendar days prior to the bid opening date. After the bid opening, the low bidder must qualify in accordance with Rule 60D-5.004, F.A.C. A copy of the requirements is included in the Non-Technical Specifications Level IV/V, Instructions to Bidders under Section B-2 “Bidder Qualification Requirements and Procedures”. Note: A completed experience questionnaire and financial statement form number DBC 5085 (Exhibit 3) must be submitted with bid.

Prior to contract award, the Department reserves the right to perform or have performed, an on-site review of the proposer’s facilities and qualifications. This review will serve to verify data and representations submitted by the proposer and may be used to determine whether the proposer has an adequate, qualified, and experienced staff, and can provide overall management facilities. The review may also serve to verify whether the proposer has financial capability adequate to meet the contract requirements. Should the Department determine that the bid/proposal has material misrepresentations or that the size or nature of the proposer’s facilities or the number of experienced personnel (including technical staff) are not adequate to ensure satisfactory contract performance, the Department has the right to reject the bid/proposal).

The respondent shall warrant that it has not employed or retained any company or person, other than a bona fide employee working solely for the respondent to solicit or secure the award for this project and that it has not paid or agreed to pay any person, company corporation, individual or firm other than a bona fide employee working solely for the respondent any fee, commission, percentage, gift or other consideration contingent upon or resulting from the award.

The respondent shall warrant that it presently has no interest and shall not acquire any interest which would conflict in any manner or degree with the performance of services required.

The respondent will comply with all applicable federal, state and local rules and regulations in providing services to the Department under this solicitation if awarded.

The employment of unauthorized aliens by any contractor/vendor is considered a violation of Section 274A(e) of the Immigration and Nationality Act. If a contractor/vendor employs unauthorized aliens, such violation shall be cause for rejection of bid/unilateral cancellation of a contract if awarded.

PUBLIC ENTITY CRIME INFORMATION STATEMENT: A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid on a contract to provide any goods or services to a public entity, may not submit a bid on a contract with a public entity for the construction or repair of a public building or public work, may not submit bids on leases of real property to a public entity, may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity, and may not transact business with any public entity in excess of the threshold amount provided in Section 287.017, F.S., for Category Two for a period of 36 months from the date of being placed on the convicted vendor list.

The STATE OF FLORIDA requires all Contractors to implement a drug free workplace program as defined in Section 287.087, Florida Statutes.

DISCRIMINATION; DENIAL OR REVOCATION FOR THE RIGHT TO TRANSACT BUSINESS WITH PUBLIC ENTITIES: An entity or affiliate who has been placed on the discriminatory vendor list may not submit a bid on a contract to provide any goods or services to a public entity, may not submit a bid on a contract with a public entity for the construction or repair of a public building or public work, may not submit bids on leases of real property to a public entity, may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity, and may not transact business with any public entity.

BID SECURITY: Bids/Proposals in total excess of $100,000.00, the bidder must provide with bid, a good faith deposit in the amount of 5% of the bid by way of a bid bond from a surety insurer authorized to do business in the STATE OF FLORIDA as surety or a certified check or cashier’s check accompanying the bid.

PERFORMANCE BOND AND LABOR AND MATERIAL PAYMENT BOND’S are required from any persons or parties entering into a formal contract with the STATE OF FLORIDA for contracts in total excess of $100,000.00 for construction, additions, renovations, repairs, or demolition of any public building pursuant to Florida Statute 255.05(1)(a).

PROCUREMENT RULES AND INFORMATION:

Contracting questions relating to this procurement should be addressed to:

Michele M. Dobbs, Contract Manager, Department of Military Affairs – CFMO, 2305 State Road 207, St. Augustine, Florida 32092, Telephone (904)823-0255 or 0256, Fax: (904)823-0189, e-Mail Address: Michele.dobbs1@fl.ngb.army.mil.

Technical questions relating to this project should be addressed to: Terry Miller, Architect/Engineer by email at tmiller@reparch.com.

INFORMATION WILL NOT BE AVAILABLE BY TELEPHONE. All information received through any oral communication shall not be binding on the Department of Military Affairs and shall not be relied upon by an offorer.

Pursuant to Section 287.057(26), Florida Statutes, Respondents to this solicitation of persons acting on their behalf may not contact, between the release of the solicitation and the end of the 72-hour period following the agency posting the notice of intended award, excluding Saturdays, Sundays, and state holidays, any employee or officer of the executive or legislative branch concerning any aspect of this solicitation, except in writing to the procurement officer or as provided in the solicitation documents. Violation of this provision may be grounds for rejecting a response.

All questions and answers/changes to the solicitation will be provided in writing and posted on the DMS Vendor Bid System (VBS). It is the prospective contractor’s responsibility to check periodically for any information updates to the solicitation which are posted to the VBS. The Department of Military Affairs bears no responsibility for any delays, or resulting impacts, associated with a prospective contractor’s failure to obtain information made available through the DMS Vendor Bid System.

CONFLICT OF INTEREST: This solicitation is subject to chapter 112 of the Florida Statutes. Respondents shall disclose with their response the name of any officer, director, employee or other agent who is also an employee of the State. Respondents shall also disclose the name of any State employee who owns, directly or indirectly an interest of five percent (5%) or more in the respondent or its affiliates.

MANDATORY PRE-BID MEETING

DATE AND TIME: August 15, 2007, 10:00 a.m. (Local Time)

PLACE: Palmetto National Guard Armory, 1107 14th Avenue West, Palmetto, Florida 34221-4544.

Sealed bids will be received, publicly opened and read aloud on:

BIDS/RESPONSES TRANSMITTED ELECTRONICALLY WILL NOT BE CONSIDERED. BIDS/RESPONSES RECEIVED AT THE LOCATION DESIGNATED AFTER THE EXACT TIME SPECIFIED FOR RECEIPT WILL NOT BE CONSIDERED.

DATE AND TIME: September 12, 2007, until 10:00 a.m. (Local Time)

PLACE: Palmetto National Guard Armory, 1107 14th Avenue West, Palmetto, Florida 34221-4544

MARK ENVELOPES: SEALED BID for Project Number 206032, Construction Facility Management Office (CFMO) Attn: Kenneth Hersey or John Brady

Bids submitted prior to the bid opening via courier or mail are to be delivered to: State of Florida, Department of Military Affairs, 2305 State Road 207, St. Augustine, Florida 32086 Marked as above. Bids must be received by this office NO LATER THAN Close of Business, September 11, 2007.

BID/PROPOSAL: All responses must be submitted in a sealed package and shall be clearly marked on the outside of package with the above information. Department of Military Affairs is not responsible for the opening of any solicitation package which is not properly marked. It is the respondent’s responsibility to assure its response is submitted in the place and time indicated in this solicitation. Also, all responses must be in full accordance with the requirements of the Drawings, Specifications, Bidding Conditions and Contractual Conditions, and Non-Technical Specifications, which have been prepared by the Engineer as listed, and may be obtained as follows:

ARCHITECT‑ENGINEER: Renker Eich Parks Architects, 1609 Dr. Martin Luther King Street North, St. Petersburg, FL 33704. TELEPHONE: (727)821-2986. All Technical Questions must be directed to Terry Miller by email at tmiller@reparch.com.

Make all checks or money orders payable to: Renker Eich Parks Architects             No Credit cards are accepted.

DEPOSIT: $200.00 per set of Drawings and Specifications is required with a limit of two (2) sets per General Contractor or Prime Bidder and one set per mechanical subcontractor and/or electrical subcontractor. The deposit shall only be returned to those General Contractors, or Prime Bidders, mechanical subcontractors and/or electrical subcontractors, who, after having examined the Drawings and Specifications:

a.     Submit a request for pre‑qualification and fail to qualify, or

b.     Submit a bid (in the case of mechanical and/or electrical subcontractor’s submission of a bid to a prime bidder), and return the Drawings and Specifications in good condition within fifteen (15) days of the date of receipt of bids.

FULL SETS of Drawings and Specifications can be purchased from the Architect for $150.00 per set.

CONTRACT AWARD: Contract Award will be on Base Bid items only. The official Notice of Award Recommendation will be by electronic posting on the Department’s website at http://fcn.state.fl.us/owa_vbs/owa/vbs_www.main_menu. Failure to file a protest within the time prescribed in Section 120.57(3), Florida Statutes, shall constitute a waiver of proceedings under Chapter 120, Florida Statutes. If no protest is filed, the contract will be awarded to the qualified, responsible and responsive low bidder in accordance with Chapter 60D-5, F.A.C. by the Owner.

INABILITY TO POST ELECTRONICALLY: If the Department is unable to post (due to technical difficulties) as defined above, the Department will notify all proposers via the Point of Contact and electronic address provided to the Department by the proposer at the Mandatory Pre-Bid meeting. Notice will be posted as defined above once the technical difficulties have been rectified; however, the official posting time will be that time at which the last proposer was electronically notified.

MINORITY PROGRAM: Minority Business Enterprises (MBE) are encouraged to participate in this Invitation to Bid. Utilization of MBE participation is highly encouraged from all Bidders. MBE’s must be certified by the Office of Supplier Diversity.

CLARIFICATIONS/REVISIONS: Before award, the Owner reserves the right to seek clarifications or request any information deemed necessary for proper evaluation of submissions from all respondents deemed eligible before Contract award. Failure to provide requested information may result in rejection of the response.

The Department reserves the right to accept or reject any or all proposals received and reserves the right to make an award with or without further discussion of the proposals submitted or accept minor informalities or irregularities in the best interest of the State of Florida, which are considered a matter of form and not substance, and the correction or waiver of which is not prejudicial to other proposers. Minor irregularities are defined as those that will not have an adverse effect on the Department’s interest and will not affect the price of the proposal by giving a proposer an advantage or benefit not enjoyed by all other proposers. It is understood the proposal will become a part of the Department’s official file, without obligation to the Department. Proposals may be rejected if found to be irregular or not in conformance with the requirements and instructions contained herein. A proposal may be found to be irregular or non-responsive by reasons that include, but are not limited to failure to utilize or complete in their entirety prescribed forms, conditional proposals, incomplete proposals, ambiguous proposals, and improper, missing and/or undated signatures.

The Non-Technical Specifications Level IV & V are considered to be applicable to this solicitation and award of contract when made and are made a part hereof. The State of Florida, Department of Military Affairs, objects to and shall not consider any additional terms or conditions submitted by a respondent, including any appearing in documents attached as part of a respondent’s response. In submitting its response, a respondent agrees that any additional terms or conditions; whether submitted intentionally or inadvertently, shall have no force or effect. Failure to comply with terms and conditions, including those specifying information that must be submitted with a response, shall be grounds for rejecting a response.

Prior to entering into a contract with the State of Florida, Department of Military Affairs, the selected contractor must be registered with the Florida Department of Management Services (DMS) MyFloridaMarketPlace Vendor Registration System. Information about the registration process is available, and registration must be completed at the MyFloridaMarketPlace website (link available under BUSSINESS at www.myflorida.com). Prospective contractors who do not have Internet access may request assistance from the MyFloridaMarketPlace Customer Service at (866)352-3776.

The State of Florida, through the Department of Management Services, has instituted MyFloridaMarketPlace, a statewide e-procurement system. Pursuant to subsection 60A-1.032(1), Florida Administrative Code, this contract shall be exempt from the one percent (1%) transaction fee.

The State of Florida’s performance and obligation to pay under this contract is contingent upon availability of funding and an annual appropriation by the Legislature.

For the purposes of this solicitation, the terms proposer, respondent, offerer and contractor/vendor are used interchangeably and mean a person(s) or firm(s) submitting a response to this solicitation, including joint ventures.

NO VERBAL STATEMENTS MADE BY ANY STATE OF FLORIDA EMPLOYEE OR AGENCY REPRESENTATIVE WILL OPERATE TO SUPERSEDE INFORMATION PUBLISHED IN THIS SOLICITATION. ONLY WRITTEN ADDENDUMS ISSUED BY THE DEPARTMENT OF MILITARY AFFAIRS CONSTRUCTION AND FACILITY MANAGEMENT OFFICE OR ITS REPRESENTATIVES WILL OPERATE TO ALTER OR OTHERWISE AMEND THIS SOLICITATION.